By using this Website or engaging with RP Home & Commercial Construction Services in any capacity, whether via online form, phone call, email, or in-person consultation, you acknowledge that you have read, understood, and voluntarily accept all terms, conditions, policies, and disclaimers outlined herein. You confirm that you are at least 18 years of age, legally capable of entering into binding agreements, and authorized to act on behalf of any individual, business, or entity for whom services may be requested.

These Terms apply to all users, including homeowners, property managers, investors, commercial clients, and contractors seeking collaboration or subcontracting opportunities.

This Website serves as an informational and marketing platform for RP Home & Commercial Construction Services. It is designed to:

• Showcase our range of residential and commercial construction services
• Provide contact information and inquiry forms for potential clients
• Share service descriptions, project highlights, and company values
• Facilitate communication between our team and prospective customers

The content provided on this Website is for general informational purposes only and does not constitute professional advice, a binding quote, or a formal offer to enter into a contract. All services are subject to assessment, site evaluation, and written agreement.

RP Home & Commercial Construction Services is a licensed and insured general contractor specializing in full-spectrum construction solutions for both residential and commercial properties. Our services include, but are not limited to:

• New Home Construction
• Home Additions & Expansions
• Kitchen Remodeling
• Bathroom Remodeling
• Roofing (Residential & Commercial)
• Vinyl Siding Installation & Replacement
• Interior & Exterior Painting
• Flooring Installation & Replacement (Hardwood, Tile, Laminate, Vinyl, etc.)
• Plumbing Services (Fixture installation, pipe repair, water heater replacement)
• Electrical Work (Wiring, panel upgrades, lighting installation)
• Excavation & Site Preparation
• Residential & Commercial Framing
• Asphalt Paving & Driveway Installation/Repair
• Landscaping & Hardscaping
• Snow Removal & Plowing (Seasonal service for homes and businesses)
• Foundation Work & Structural Repairs
• Permit Assistance & Code Compliance Guidance

We proudly operate under the motto: “No job is too big or too small!” meaning we accept projects of all sizes and complexities, from minor repairs to full-scale builds.

Non-Binding Nature of Estimates

Any estimate, quote, or price range provided through the Website (via contact form, email, phone, or in-person) is non-binding, time-sensitive, and subject to change based on:

• Site conditions discovered during inspection
• Fluctuations in material costs (e.g., lumber, roofing, asphalt)
• Changes in project scope or design
• Unforeseen structural or environmental issues
• Permitting requirements or local regulations

Unless otherwise stated in writing, all estimates are valid for 30 days from the date issued.

Accuracy of Information

Clients are responsible for providing accurate and complete information about their property, desired work, and budget expectations. Inaccurate details may result in incorrect estimates or delays.

No Guarantee of Final Price

While we strive to honor quoted prices, significant changes in scope, materials, or unforeseen complications may require adjustments. Any revised pricing will be communicated in writing before proceeding.

Formal Agreement Required

No work will begin until a written service agreement has been signed by both RP Home & Commercial Construction Services and the client. This agreement will include:

• Detailed scope of work
• Project timeline
• Total cost and payment schedule
• Material specifications
• Warranty information
• Cancellation and change policies

Deposit Requirements

A deposit may be required to secure project scheduling. The amount (typically 10–30% of total cost) will be specified in the contract. Deposits are non-refundable once materials have been ordered or work has commenced, except as required by Massachusetts law.

Right to Decline Service

We reserve the right to decline any project or client for any reason, including but not limited to safety concerns, non-payment history, unrealistic expectations, or unsafe working conditions.

Clients agree to:

• Provide safe, timely, and unobstructed access to the property
• Disclose known structural, electrical, plumbing, or environmental issues
• Obtain homeowner association (HOA) approvals if required
• Secure necessary permits if not included in the contract
• Communicate changes or concerns promptly
• Maintain clear communication throughout the project

Failure to meet these responsibilities may result in project delays, additional fees, or termination of services.

Payment Schedule

Payments will follow the schedule outlined in the service agreement, which may include:

• Initial deposit upon signing
• Progress payments at key milestones
• Final payment upon completion and client approval

Accepted Payment Methods

We accept:

• Cash
• Check (payable to RP Home & Commercial Construction Services)
• Bank transfer (ACH/electronic payment)

Credit cards and financing options are not currently offered unless otherwise arranged in writing.

Late Payments

If a payment is overdue by more than 15 days, work may be suspended until payment is received. Late payments may incur administrative fees.

Any changes requested by the client after the contract is signed, including design modifications, material upgrades, or additional work will be documented in a Change Order. The Change Order will specify:

• Description of changes
• Impact on timeline
• Additional costs (if any)

Work will not proceed on changed items until the Change Order is approved and signed by both parties.

Client Cancellation

• If canceled before work begins, the deposit may be refunded minus administrative costs, at our discretion.
• If canceled after work begins, the client is responsible for all labor, materials, and expenses incurred up to the cancellation date.

Contractor Rescheduling

We may reschedule work due to:

• Inclement weather (especially for roofing, paving, excavation)
• Material delivery delays
• Unforeseen site conditions
• Labor availability

We will notify clients as soon as possible and work to minimize disruption.

Labor Warranty

We provide a 1-year labor warranty on all construction and remodeling work, covering defects in workmanship under normal use. This warranty does not cover:

• Damage caused by misuse, accidents, or natural disasters
• Normal wear and tear
• Issues arising from client-made modifications
• Problems due to lack of maintenance

Material Warranties

Warranties on materials (e.g., roofing shingles, vinyl siding, flooring) are provided by the manufacturer and vary by product. We will assist in filing claims where applicable.

Warranty Claims Process

To file a warranty claim, contact us in writing within the warranty period. We will inspect the issue and determine eligibility for repair or replacement.

To the fullest extent permitted by Massachusetts law, RP Home & Commercial Construction Services shall not be liable for:

• Any indirect, incidental, consequential, or punitive damages
• Delays caused by factors beyond our control (weather, supply chain, permitting)
• Pre-existing conditions not disclosed by the client
• Damage to personal property unless caused by gross negligence
• Injuries to clients, visitors, or pets during active construction

Our total liability for any claim related to our services or Website shall not exceed the total amount paid by the client for the specific service in question.

We strongly recommend that clients maintain appropriate homeowner’s or commercial property insurance during construction.

You agree to use this Website lawfully and responsibly. Prohibited activities include:

• Submitting false, misleading, or fraudulent information
• Attempting to hack, disrupt, or overload the Website
• Scraping, copying, or redistributing content without permission
• Using automated tools (bots, crawlers) without consent
• Impersonating our company or employees

We reserve the right to block IP addresses, disable form access, or pursue legal action for violations.

All content on this Website, including text, images, graphics, logos, videos, design elements, and source code, is the exclusive property of RP Home & Commercial Construction Services and protected under U.S. copyright, trademark, and intellectual property laws.

You may not:

• Reproduce, distribute, or display any content without written permission
• Use our logo, business name, or branding for promotional purposes
• Claim ownership or authorship of our materials

Authorized use is limited to personal, non-commercial viewing and inquiry submission.

This Website may contain hyperlinks to third-party websites, such as:

• Material suppliers (e.g., GAF, James Hardie)
• Local government permitting portals
• Industry associations
• Social media platforms

We do not control these sites, have no responsibility for their content, privacy practices, or accuracy, and do not endorse any products or services advertised on them.

Any personal information collected through this Website (name, address, phone, email, project details) is used solely to:

• Respond to inquiries
• Provide service estimates
• Schedule consultations
• Manage client relationships

We do not sell, rent, or share your data with third parties for marketing purposes. Data is stored securely and retained only as long as necessary. For full details, please review our Privacy Policy.

Informal Resolution

We encourage clients to contact us directly to resolve any concerns. Most issues can be settled through open communication.

Mediation and Arbitration

If unresolved, disputes will be submitted to mediation in Brockton, Plymouth County, Massachusetts. If mediation fails, disputes may proceed to binding arbitration or small claims court.

Governing Law

These Terms are governed by the laws of the Commonwealth of Massachusetts, without regard to conflict of law principles.

You agree to indemnify and hold harmless RP Home & Commercial Construction Services, its owners, employees, and agents from any claims, damages, losses, or expenses (including legal fees) arising from:

• Your use of this Website
• False information provided by you
• Unauthorized modifications to your property post-completion
• Injury or damage caused by your negligence during or after construction

We reserve the right to update, revise, or replace these Terms and Conditions at any time. Changes will be posted on this page with a new “Last Updated” date. Continued use of the Website or services after changes constitutes acceptance of the revised Terms.

For questions about these Terms and Conditions, service inquiries, or complaints, please contact us:

RP Home & Commercial Construction Services
Brockton, MA

508 232 8960

Rudy@rpconstructionservice.com

www.rpconstructionservice.com